Human behaviour Essay Example for Free

Human behaviour Essay Arthur Millers The crucible is a play that shows the extremes of human behaviour both good and bad. In this essay I will be discussing these extremes and also hope the essay will help me conclude whether the best or the worst of human behaviour is presented more strongly. I will also aim to link these themes to events, which would have affected the author at the time the play written. I will give examples of each type of behaviour and conclude. I will start by explaining about the background of the crucible. Arthur Miller wrote it in 1950s America but it is set in Salem 1692. Salem was a puritan community that because of the time had very little scientific knowledge so blamed any unexplained happenings on witchcraft. If someone was accused of witchcraft and confessed they were saved from being hanged but if they denied the charges then they were almost definitely hanged. This is how the witch-hunt began, people would be accused and they would confess and blame others and in turn the others accused would accuse someone else. Millers reasons for writing this play were mainly because the events happening in the 1950s America. At this time in America a modern day witch hunt was taking place. But instead of witches they were hunting communists. Communism is a political theory that states that everyone in society is equally wealthy. Russia had already had a communist revolution and communism had spread to China also. This was the cause of much conflict in Vietnam in which America was heavily involved. The American government was afraid that communism would spread to America and the people would overthrow the government. Also communism clashes with the right wing policies of the American government. Senator Joseph McCarthy was a main figure in this and so this was called McCarthyism. They tackled the threat of communism by passing laws to restrict the actions of communist supporters. Arthur Miller himself was accused of being a communist and like many others would have been questioned about his friends, family and political beliefs and also asked to name others involved. In response to this Arthur Miller wrote the crucible to try and show how the hysteria in the 1950s was similar to the hysteria in Salem 1692. The worst of the behaviour in The crucible is shown mainly in the character Abigail Williams. Abigail is from the very beginning a central character in the play and uses most of her time in the play to seek revenge on one woman, Elizabeth Proctor. She manipulates the court and the other girls into helping her with her plan under the pretence of doing Gods work. It is clear from the very beginning of the play that Abigail bears a grudge against Elizabeth from the language used. Cold imagery is used when Abigail describes Elizabeth; Its a bitter woman, a lying, cold, snivelling woman(act1). The reason for this is because John Proctor, Elizabeths husband had an affair with Abigail and Elizabeth subsequently sacked Abigail. Abigail is still in love with John and hopes that if Elizabeth is hanged then John will want her back. Miller helps us understand the passion of the love Abigail feels for John by the hot imagery used; I have a sense for heat, Johnand I have seen you looking up, burning in your loneliness(act 1). Abigail realising her power over the court goes about accusing anybody she can think of. There are a few people however who doubt her however Elizabeth, John and reverend Hale but none of them can stop her. She carries on accusing people up until the end of act three where John Proctor confesses to the court that he had an affair with Abigail and calls her many names whore and Harlot. Abigail then realises that John does not love her and she steals all of her uncles money and runs away with Mercy Lewis another of the girls. Abigail is a character who is selfish and manipulating and one who shows no compassion to those who she falsely accuses. I think this character was not one that the audience would ever feel sorry for because of the way she is portrayed by Miller. I myself felt angry at the character and I think this was because she shows no remorse and even while other characters see the error of their ways and try and put things right she never even attempts to clear her conscience. Another Character who displays one of the worst examples of behaviour is Reverend Parris who is Abigails uncle. Although he does not cause as much trouble as his niece he is a character that is portrayed by Miller as a self-absorbed and selfish. This is portrayed in many ways; one of them is in Act 1 when although he is upset about his daughter he still has time to question Abigail about their actions in the woods. This may have at first seemed like concern for his child (Betty) but then miller slowly brings the audience to realise that he is only worried that his reputation may be damaged a quote which shows this is But if you trafficked with spirits in the forest I must know it now, for surely me enemies will, and they will ruin me with it(act 1). Another is that he is extremely vain and thinks that he deserves the deeds to the house set aside for the minister and although he now owns the house he still talks of more money he needs. John Proctor says something that really sums up Parris vanity Since we built the church there were pewter candlesticks upon the altar But Parris came, and for twenty week he preach nothin but golden candlesticks until he had them(act 2) which shows even though he preaches the puritan way of life he wants the luxuries no-one else is allowed. Even at the end of the play when most of the characters are trying to help John Proctor the only thing Parris is worried about is himself and that there will be a rebellion against the church if Proctor is hanged. Parris pathetic character is shown most prominently at the end mainly in the stage directions which show him sobbing because he has no money and is once again concerned for himself when he starts talking about how much danger he is in You cannot hang this sort. There is danger for me. I dare not step outside at night!

Construction Project Delay: Causes and Effects

Construction Project Delay: Causes and Effects In this chapter, I will discuss types, causes and effects of delay of project in the construction industry. Besides that, I will also discuss the method to minimize the delays happening in construction industry 2.2 Type of Delay In construction industry, there are the categories of delays used in determining delay damage as shown in table 2.1 Figure 2.1 Types of Delay 2.2.1 Excusable delays Excusable delay as define a delay that is due to an unforeseeable event beyond the contractorà ¢Ã¢â€š ¬Ã¢â€ž ¢s or the subcontractorà ¢Ã¢â€š ¬Ã¢â€ž ¢s control. Usually, based on common general provisions in public agency specifications, delay resulting from the following events would be considered excusable such as fires, floods, owner-directed changes, errors and omissions in the contract drawing, unusually severe weather and etc. Excusable delays can be further classified into excusable with compensation and excusable without compensation. 2.2.1.1 Excusable with compensation Compensation delays are caused by the owner or the owners agents. An example of this would be the drawings late release from the owners architect. An excusable, compensable delay normally leads to a schedule extension and exposes the owner to financial damages claimed by the contractor. In this scenario, the contractor incurs additional indirect costs for both extended field office and home office overhead and unabsorbed home office overhead. 2.2.1.2 Excusable delays without compensation Non-compensable delays are caused by third parties or incidents beyond the control of both the owner and the contractor. Examples typically include acts of God, unusual weather, strikes, fires, acts of government in its sovereign capacity, etc. In this case, the contractor is normally entitled to claim extension of time but no compensation for delay damages 2.2.2 Non-excusable delays Non-excusable delays are cause by lack of performance of the contractor on the construction project. This delay can be cause by underestimates of productivity, improper project planning and scheduling, poor site management and supervision, wrong construction methods, equipment breakdowns, unreliable subcontractors or suppliers. Therefore, it is contractor responsibilities to continue their work with no entitlement to claim for extension of time or delay damages until they completed the project. For instance, a contractor failure to provide an adequate material to completed their job. 2.2.3 Concurrent Delay Concurrent delay is a problem that happening on most of the construction industry project. This issue arises when two or more delaying event at the same time in a project cannot complete on time. In this situation, both owner and contractor are responsible for the delay. Commonly concurrent delays which involve any two or more excusable delays result in extension of time. When excusable with compensation and non-excusable delays are concurrent, an extension of time can be issued or the delay can be distribution between the owner and the contractor. Concurrent delay can be categories in three types of delays: If excusable and non-excusable delays occur concurrently, the contractor only to allow claim for extension of time: If excusable with compensation and excusable without compensation delays occur concurrently, the contractor is entitle to claim extension of time but no delay damages: If two excusable with compensation delays occur concurrently, the contractor is entitled to claim extension of time and delay damages. For instance, a concurrent delay would be if the owner failure to give more detail regarding either using ceramic tile or homogeneous tile for toilet floor finishes. But at the same time contractor made with own decision and using ceramic tile for toilet floor finishes but actually owner plan using homogeneous tile. In this situation, the contractor cannot claim for damages. It is because contractor is not follow owner instruction but he can claim for extension of time with owner failure to give more detail of drawing 2.3 Causes of delays Figure 2.2 Causes of delays Based on the researched done through by journal, books, and some other reference. Project delay can be causes by a lot of parties which is shown in the Figure 2.2. They are include client, contractor, consultant, labour, material, equipment, financial and some external causes. 2.3.1 Caused of Client Related Delays Figure 2.3 Factors of client related delays 2.3.1.1 Lack of experience of client in construction According to Koushki, et al. (2005) identified factors of lack of experiences of client in construction project have high influence to the causes of delays. Some of the project delay cause by client due to not enough experience especially fresh developer. Most of the time, client facing a problem and do not know how to solve it immediately because of no experience. During client finding the way to solve the problem, some of the work could not progress. Finally, the whole project delay because of some particular work delay. 2.3.1.2 Change order According to Odeh and Battaineh (2002) mentioned the factors of change orders that contribute to causes of delaysà ¢Ã¢â€š ¬?. Client always change the design during the construction period, during the same time that will affect whole project delay. It is because contractor cannot carry out his work until the latest drawing issue by architect. Consequently contractor cannot be done within the contract period. Most of the current project delay because of change order by client. For instance, a project almost complete but client change certain part of design and instruct contractor carry out the additional work. After done the whole project, the contractor found out was exceeding contract period. 2.3.1.3 Client interference According to Long, et al. (2004) studied the factors client interference that contributes to causes of delays in construction project. Some of the client instruct contractor to carry out additional work without ask architect promise. During the contractor carry out additional work, some of the work could not progress and it will be delay immediately. On the other hand, client do not follow the procedure such as did not mention architect issue an architect instruction. Finally it will affect the whole project delay. 2.3.2 Causes of contractor related delay Figure 2.4 Factors of contractor related delay 2.3.2.1 Inadequate contractor experience Abd Majid and McCaffer (1998) studied the factors of inadequate contractor experience as contributor to causes of delays. Long, ET al. (2004) mentioned the factors of inadequate contractor experience that contribute to causes of delays in construction project. Battaineh (2002) identified the factors of inadequate contractor experience as contributors to causes of delays. In construction industry, some of the delay projects are facing a problem during construction period. But at the same time contractor could not solved the problem immediately because of no experience. During the contractor finding method to solve the problem, some of the works totally stop because of that problem. After the problem was solved, those work keeping continue but run out from the schedule. Finally, the whole project will influence delay. 2.3.2.2 Inaccurate time estimate According to Long, et al. (2004) identified the factors of inaccurate time estimating that contribute to causes of delays in construction project.à ¢Ã¢â€š ¬? Time estimates are important as inputs into other technique used to manage and structure for all projects. An inaccurate time estimation technique may cause a project delay. For instance, in some delay project, the contractor do not allowed time for some common problem always happen during the construction stage such as breakdown of equipment, miss deliveries by supplies, accidents and emergencies and so on. Because of this problem the actual time will run out from the estimated. So, the whole project could be facing delay. 2.3.2.3 Inaccurate of cost estimate According to Long, et al. (2004) also mentioned that, the factors of inaccurate cost estimating that contribute to causes of delays in construction project. Construction estimating errors can be very expensive and embarrassing. Inaccurate of cost estimate contribute a lot of cause such as wrong measurements from contract drawing, using incorrect units of measure, material improperly priced and the most common mistakes in arithmetic . Sometime contractor because of inaccurate of cost estimate measurement again for that particular work. Finally, due to re-measurement time some of the work will influence delay and it will also affect whole project to delay. 2.3.2.4 Poor site management and supervision Battaineh (2002) studied that, the factors of poor site management and supervision as contributors to causes of delays. Chan and Kumaraswamy (1996) identified the factors of poor site management and supervision that contribute to causes of delays. In construction industry, some of the project team a lack of management and supervision due team member without any experience and skill such as hire person who are fresh graduate. Once they facing problem but do not know how to solve it. Besides that, some of the supervisor did not cooperation with their team member due to lack of communicated. Finally, because of cannot solve the problem immediately the whole project influence delay. 2.3.3 Causes of Consultant Related Delays Figure 2.5 Factors of consultant related delays 2.3.3.1 Inadequate consultant experience According to Long, et al. (2004) studied the factors of inadequate consultant experience as contributors to causes of delays. In construction industry, they are many consultants carry out their work without experience. Besides that, there are many causes of a consultant without experience which include different site conditions, mismanagement and maladministration, site access restrictions, defective plan and/or specification. For instances, some of the architects only concentrated in certain part of building and do not have any experience in other type. Once architect design on that particular type of building without experiences, he will facing a lot of mistake and no ideas during design and because of this architect will delay issue the drawing. Finally, the works cannot process and it will affect the whole project delay. 2.3.3.2 Poor design and delay in design According to Ogunlana, et al.(1996) mentioned the factors of poor design and delay in design that contribute to causes of delays in construction project. Design is every important to any project, without good design the whole project will influence delay. It is because in a project if facing poor design that will facing demolish and rebuilt again. This problem happens because of the designer lack of experience. For instance, an architect designs a column in the middle of classroom. Once the contractor without any experience and construct the work exactly shown in the drawing. Finally 2.3.3.3 Incomplete drawing and detail design Long, et al. (2004) identified the factors of incomplete drawing and detail design as contributors to causes of delays. Ogunlana, et al. (1996) studied the factors of incomplete drawing and detail design that contribute to causes of delays in construction project. During construction, the contractor is carrying out the work but because of drawing is unclear and none very detail shown in the drawing. He could not continue the work with problem, so the works have to stop immediately until get more detail of that particular drawing from consultant responds. Because of without detail drawing the work could not be progress, so it will affect the tat particular work delay and it will also influence the whole project delay. 2.3.4 Causes of labour related delays Figure 2.6 Factors of labour related delays 2.3.4.1 Labour supply Abd Majid and McCaffer (1998) identified the factors of slow labor supply that contribute to causes of delays. Odeh and Bataineh (2002) in their research identified à ¢Ã¢â€š ¬Ã…“the factors of labor supply as contributors to causes of delays. Besides material, the labour also consider as major source in the construction industry. Generally, labour are categories into two groups such as skilled workers and unskilled workers. In construction industry without labour project could not run. For instance, during construction, materials are ready to but no worker carrying out the work. During the same time because of no worker to progress of work, the project will confront project delay. 2.3.4.2 Shortage of skilled worker According to Chan and Kumaraswamy (1996) mentioned the factor of shortage of skill labor is the most important factor that contributed to causes of delays. Skilled worker is a worker who has some special skill, knowledge and ability in his job and also gets highest pay such as plasterer, carpenter, painter, and concreter. Those skilled workers are learning the skills on the job. In construction, some contractors do not hire skilled workers because of higher labour cost and he employs some unskilled workers. At the same time skilled workers do not want get the job from the contractor with lower labour cost. Finally the unskilled workers could not complete the work on time. So, because of shortage of skilled worker affect whole project delay. 2.3.4.3 Labor of productivity According to Ogunlana, et al. (1996) studied the factor of labor productivity having high influence to causes of delays. Labor of productivity; generally define as output per labour hour. There are many factors that influence on the labour productivity. One of the factors is workers experience, labour with high experience and high skills in field leads to high performance at workplace. Besides that, attitude also will affect productivity of labour. For instance, a worker can lay one meter square per hour but because of lazy. Finally he using three hours to finish laid the brick wall. Because of this factor, the progress work delay and it will also influence the whole project delay. 2.3.5 Causes of Material related Delay Figure 2.7 Factors of material related delay 2.3.5.1 Shortage of construction materials Koushki, et al. (2005) mentioned that, factor shortage of construction material that contribute to causes of delays. Ogunlana, et al. (1996) identified the factor of shortage of material as a factor to causes of delay. Chan and Kumaraswamy (1996) studied that factors shortage of material as contributors that contribute to causes of delays. Abd Majid and McCaffer (1998) identified the factor of shortage of material that contribute to causes of delays. Material shortage is a potential source of construction delay. The major causes of material shortage is demand exceed supply. In construction have a lot type of material and the three main courses are cement, formwork and steel bar. Besides that, material is one of the main sources in construction industry. It is because without material project cannot construct. If a project facing the material shortage problem will be delay. For instance, a project having shortage ceramic tiles even though the labours ready for tiling. In this situatio n, the project will facing delay project. 2.3.5.2 Late delivery of materials Ogunlana, et al. (1996) identified the factor of late delivery of material as a factor to causes of delay. Abd Majid and McCaffer (1998) studied the factor of late delivery of material that contribute to causes of delays. Late delivery of material as a supplier fault due to high market demand; however the long procedure of the purchasing order from head office was complained. In construction, it factor is similar to the material shortage such as the labour ready for work but no material to do their work. Once contractor cannot receive the material on time that will be delay work and it will also affect project delay. For example, workers want to install the windows but without frame because of late delivery to site. So, the work will be delay and it will affect project delay. 2.3.5.3 Poor quality of construction materials Koushki, et al. (2005) mentioned that factor poor quality of material that contribute to causes of delays. Ogunlana, et al. (1996) identified the factor of poor quality of material as a factor to causes of delay. Abd Majid and McCaffer (1998) studied the factor of poor quality of material that contribute to causes of delays. Poor quality of material is construct building with using poor quality of material. The contractor has intention to cheat owner to earn more profit by change the quality of material such as concrete. For instance, a contractor cast a column with using Y 20 steel bar but actual in contract drawing is Y 25. After site staff done the inspection for this column and found that the steel bar inside column is Y 20 and ask contractor demolish the column to rebuild. In this case, time taken to rebuild the column will also affect project delay. 2.3.5.4 Escalation of material prices Ogunlana, et al. (1996) identified the factor of escalation of material prices as a factor to causes of delay. Wiguna and Scoot (2005) studied the factor of escalation of material prices was one factor that contribute to causes of delays. Escalation of material prices will cause shortage material in construction. It is because the market rate is keeping increasing. Some of the contractor does not buy the expensive material. During same time, the construction without material cannot run so the project will influence the project delay. For instance, a contractor because of material cost of market demands higher and does not make any order for material until material shortage. Finally, the construction cannot run without material and it will affect delay project also. 2.3.6 Causes of Equipment Related Delays Figure 2.8 Factors of Equipment related delays 2.3.6.1 Insufficient number of equipment According to Ogunlana, et al. (1998) identified the factors of insufficient numbers of equipment is the most significant factors that contribute to causes of delays. In construction stage, contractors are facing not enough machinery to produce work. It is because some of the contractors do not have a large capital to purchase that machinery due to higher cost. Once the projects carry out with not enough machinery, it will influence whole project delay. For instance, there are two works to be done by using towel crane but in site only one towel crane available. Finally, two of work could not be done at the same time due to not enough towel cranes. 2.3.6.2 Frequent equipment breakdown McCaffer (1998) studied the factors of equipment breakdown as contributors to causes of delays. Ogunlana, et al. (1998) mentioned the factor of frequent equipment breakdown is the most significant factors that contribute to causes of delays. In construction industry, some of the machinery always breakdown due to improper using by worker such as do not follow the instruction. For instance, machinery only can support for five hundred kilograms of material but during worker using that machinery and his carry out six hundred kilograms of material. Finally, the machinery will breakdown. Once machinery breakdown, the work will be stop immediately and affect some work delay. Finally, because of machinery breakdown the whole project will also influence delay. 2.3.6.3 Shortage of Equipment Parts According to Chan and Kumaraswamy (1996) identified the factor of shortage of equipment parts that contribute to causes of delays. After machinery breakdown, the technical carry out the repair work for the breakdown of equipment. During the same time, some part of machinery none have stock in market. Because of no spare part to repair the machinery, some of the works facing stop progress immediately. Consequently, it will influence whole project to be delay. 2.3.7 Causes of Financial Related Delays Figure 2.9 Factors of Financial related delays 2.3.7.1 Clientà ¢Ã¢â€š ¬Ã¢â€ž ¢s financial difficulties According to Chan and Kumaraswamy (1996) identified the factors of clientà ¢Ã¢â€š ¬Ã¢â€ž ¢s financial difficulties as contributor to causes of delays. During the construction, client will face some financial problem arise from unanticipated emergencies or financial mismanagement such as global financial crisis. Besides that, a client proposes a new development without borrow term loan or bridging loan from the bank. On the other hand, improper cost planning is a most serious problem for those clients facing in current delay project. For instance, during pre-construction stage a client do not planning cost properly and he will facing a lot of problem in construction stage such as no enough capital to pay contractor payment. Finally, because of contractor did not receive payment to influence whole project delay. 2.3.7.2 Delay payment to suppliers/subcontractor According to Abd Majid and McCaffer (1998) mentioned the factors of inadequate fund allocation and delay payment to subcontractor/suppliers as contributor to causes of delays in construction project. Due to sub- contractor do not take their responsibility to done the work on time. The contractor will delay the payment until they complete the job. But at the same time, the sub-contractor refuse to work because of not yet receive payment. As a consequently, the whole project will be influence delay due to sub-contractor refuse to work. 2.3.7.3 Contractorà ¢Ã¢â€š ¬Ã¢â€ž ¢s financial difficulties According to Ogunlana, et al. (1996) studied the factors of contractorà ¢Ã¢â€š ¬Ã¢â€ž ¢s financial difficulties having high influence to causes of delays. Poor financial management has been known as one of the factors why certain project cannot complete within contract period. Because of contractor lack of experience and could not manage their capital properly. On the other hand, because of delay payment by client contractor not enough money to cover up all sub-contractors and suppliers payment. Finally, the sub-contractor and suppliers refuse to work and supply material to the site and because of this factor the whole will influence delay. 2.3.8 Causes of External Related Delays Figure 2.10 Factors of external related delays 2.3.8.1 Weather condition Odeh and Battaineh (2002) identified the factors of weather condition as contributors to causes of delays. Long, et al. (2004) mentioned factors weather condition as factors ofexternal related delays. AL-Momani (2000) studied the factor of weather condition as contributors to causes of delays in construction project. During the construction period, weather is a factor to influence the whole project delay. It because weather condition that interfere with planned activities. Some activities can process but other cannot. For instances, during the worker cast the ground floor slab, but because of raining that particular work to be delay. 2.3.8.2 Slow site clearance According to Long, et al. (2004) identified factors of slow site clearance as factors of external related delays. During begin of construction stage, the responsibility party should have to carry out their work for site clearance immediately. Without clearance the site construction work cannot process. In some delay project found that, the third party did not take their responsibility to finish the site clearance within the period. Consequently, the whole project delay because of site clearance works delay. 2.4 Effect of Delays According to Aibinu and Jagboro (2002) identified the effects of construction delays on project delivery in Nigerian construction industry. They also said that the six major effects of delays follow by rank which include time overrun, cost overrun, dispute, arbitration, litigation, and total abandonment as shown in the Table 2.11 Effects of Delay Rank Time overrun 1 Cost overrun 2 Dispute 3 Arbitration 4 Litigation 5 Total Abandonment 6 Source : Aibinu and Jagboro (2002) Table 2.11 The effect of delays 2.4.1 Time overrun Time overrun it mean contractor could not carry out their work within contract period. In generally, time overrun can be categories into two group which include excusable delays and non-excusable. Once the project facing time overrun, it will affect the progress of work cannot finish on time. Besides that, the fault party will take the responsibility to pay the relevant parties for damages because of delay. For instance, during the project almost completed, but at the same time contractor because of exceptionally implement weather cannot completed the project within contract period. In this situation the contractor entitle to claim extension of time. On the other hand, if that contractor cannot complete the work within contract period due to his own fault. So the contractor no entitle to claim extension of time and he need to pay liquated damages. As stated in Persatuan Arkitek Malaysia form 2006 (PAM form 2006), which certain clauses stating about the damages by employer due to this event. It stated that in clauses below. 2.3.1.1 Clause 22.1 Liquidated Damage and Certificate of Non-Completion If the contractor fails to complete the works by the Completion Date, and the architect is of the opinion that the same ought reasonably so to have been completed, the architect shall issue a certificate of Non-completion. Upon the issuance of the certificate of Non-Completion the contractor shall pay or allow to the Employer a sum calculated at the rate stated in the Appendix as Liquidated Damages for the period from the Completion Date to the Date of Practical Completion. The Employer may recover such sum from the Performance Bond. The Employer shall inform the contractor in writing of such deduction or such debt due to from the contractor. The imposition of Liquated Damages by the Employer shall not be taken into account by the Architect in the issuance of payment certificates and Final Certificate, and is not subject to the set-off procedures under clause 30.4 and adjudication. 2.3.1.2 Clause 23.1 Submission of notice and particulars for extension of time If the Contractor is of the opinion that the completion of the Work is or will be delayed beyond the completion Date by any of the Relevant Event stated in Clause 23.8, he may apply for an extension of time provided always that 2.3.1.3 Clause 23.8 Relevant Events Exceptionally implement weather 2.4.2 Cost overrun During construction stages, the client and contractor always facing of cost overrun. Cost overrun  is an unexpected  cost  incurred in excess of a budgeted amount, due to  cost underestimation. Cost overrun is related to time overrun, once a project cannot be done in time, it will also affect the cost of project over budget. Commonly, cost overrun always happen due to contractor own fault such as inaccurate of cost estimate and he need to take responsibility to pay owner loss and expense. For instance, a contractor because of improper cost planning due to cost overrun. Finally, the owner set of his loss and expense from the contractor interim payment. 2.4.3 Dispute In construction industry, some of project delay because of dispute between contractual parties such as client, consultants, contractor and some relevant parties. Those disputes because of client failure make payment to the contractor. Once dispute happen, the relevant parties will go through with mediation. The mediator will make a decision to solve the problem. But if one of the parties does not accept the decision made by mediator, the parties will appeal the decision with arbitrator. If both parties accept the decision and the fault parties will take responsibility to pay damages for project delay. 2.4.4 Arbitration In current delay project, some of the contractual parties do not accept the mediator decision and they appeal in arbitration. Arbitrator will also make the decision to solve the problem. But if one of the parties does not accept the decision again made by Arbitrator, they still can appeal the decision in litigation. 2.4.5 Litigation In some delay project, the relevant parties because of still do not accept with the arbitrator decision. They are appeal the result in litigation which is dispute resolution in the courts. In litigation, the parties have a trial either by a court alone or by jury. If those parties are not satisfied judgment again, then they can appeal again if they have any new evidence to proof their right. But one the parties accept with the judgment, the faulty of parties need take responsibility to pay the penalty 2.4.6 Total abandonment Total abandonment it means the whole project stop immediately because of client facing financial difficulties. Some of the current delay project totally abandoned because of clientà ¢Ã¢â€š ¬Ã¢â€ž ¢s or contractor problem which include clients bankruptcy, contractor run away, poor marketing and sales strategies and so on. The effect of project totally abandoned will affect many parties such as contractual parties which include contractor, consultant, sub-contractor, supplier and some other relevant parties. Besides those parties, the purchasers will also suffer in cost damages due to project abandoned. 2.5 Methods of minimizing construction delays According to Nguyen, et al. (2004), à ¢Ã¢â€š ¬Ã…“studied the factors that can be applied as a method of minimizing of construction delays as follows: competent project manager; frequent progress meeting; accurate initial cost estimates; accurate initial time estimates; awarding bids to the right/experience consultant and contractor.à ¢Ã¢â€š ¬? During pre-construction stage, a client should employ a depth knowledge project manager to organize a good project team member to progress the work. Besides that, the project team member should be always discussing with the problem having during the site progress. On the other hand, contractor should be employs some employee with experience such as quantity surveyor. So that, during the time or cost estimate they can add on some unforeseen event to avoid the cost and time overrun. Furthermore, the developer should be hire some experience consultant and contractor.iot is because once they facing problem, they can refer previous project to so lve the problem immediately. So, the project can process with smoothly. According to Aibinu and Jagboro (2002), à ¢Ã¢â€š ¬Ã…“identified two methods to minimize or if possible eliminate time overrun were: acceleration of site activities, and contingency allowance.à ¢Ã¢â€š ¬? During construction stages, the contractor should carry out his responsibility to make sure the work progress can complete in time. If found that work progress are not equal to the estimate schedule. The contractor may carry out with acceleration such as hire additional worker. Besides that, the client may allow contractor standby some extra cost for unforeseen event such as accidents. According to Koushki, et al. (2005), à ¢Ã¢â€š ¬Ã…“revealed that the minimization of time delays and cost overruns would require: ensure adequate and available source of finance until project completion; ensure timely delivery of materials.à ¢Ã¢â€š ¬? During pre-construction, a client may prepare a good cash flow within the contract period. Once the client does not enough money to cover up construction cost, he can borrow a term loan or bridging loan from the bank to cover the cost until the whole project completed. It will avoid project delay due to client not enough capital. Besides that, the contractors make sure that material are order with a reliable suppliers and can receive it on time. Acco

Christo And Jean Claude Cultural Studies Essay

Christo And Jean Claude Cultural Studies Essay Christo and Jeanne-Claude have many interesting pieces of work ranging from their first Documenta 4 to The Gates. I will be covering some of their major works; such as, Wrapped Coast, Valley Curtain, Running Fence, Surrounded Islands, Reichstag, and The Gates. I have always enjoyed big installations because the work has always astounded me; the sheer size of the pieces is amazing. Close to the end of 1969, Christo and Jeanne-Claude wrapped the coast of Little Bay, in Sydney, Australia, as a part of the Alcorso-Sekers Travelling Scholarship. With the support of the John Kaldor, this was their first trip to Australia for international artists, and the first in the series of Kaldor Public Art Projects. One hundred workers and eleven volunteers devoted over seventeen thousand work hours to make this project a reality. They wrapped two and a half kilometers of coast and cliffs up to twenty-six meters high. Ninety-five thousand six hundred m^2 of synthetic fabric and 56 km of rope was required to finish this astounding project. At the time, it was the single largest piece of art ever made. This project was bigger than Mount Rushmore, and it visitors took over an hour to walk from one end of the piece to the other. Reactions were largely positive and had a very large impact on Australian art. The Valley Curtain art project was started with preparations at the end of the 1970s. This project was a four hundred meter long cloth stretched across Rifle Gap. Rifle Gap is a valley in the Rocky Mountains near Rifle, Colorado. It required about fourteen thousand m^2 of cloth to be hung on four steel cables, fastened with iron, and fixed in concrete on the slopes and two hundred tons of concrete. This project cost over $400,000. Trying to finance this huge piece was an additional problem, and it caused them to sell some of their other works to raise the money. On October 10, 1971, the curtain was ready for hanging. Unfortunately, the curtain had been torn to pieces by the wind beating it against the rocks. On August 10th of the next year, the second attempt to hang the cloth was a success. Unfortunately, only a day later, it was destroyed by a storm with winds reaching speeds in excess of sixty miles per hour. The Running Fence was completed on September 10, 1976. The workers waited fourteen days, but then they removed everything, leaving not a trace. This piece consisted of a fence almost twenty-five miles long, extending across the hills of Sonoma and Marin counties in northern California. This fence was eighteen feet high and was composed of two thousand and fifty panels of white nylon fabric hung from steel cables by the means of three hundred fifty thousand hooks. Supporting these hooks where about two thousand steel poles stuck into the ground and being braced by steel guide wires that were anchored to the ground. This piece began near U.S. Highway 101 and crossed fourteen roads, the private properties of fifty-nine ranchers to reach the Bodega Bay of the Pacific Ocean. The environmental impact report that was required for this gigantic piece was an astounding four hundred and fifty pages long. This piece is said to have been partly inspired by fences demarcating the Continental Divi de in Colorado. In 1978, a documentary film Running Fence by Albert and David Maysles, told the story of this piece. This film includes scenes showing the local response to the project, which ranged from active protest and resentment to excitement. Byron Randall, the expressionist painter, protested the piece on the grounds of both land infringement and lack of artistic merit; however, others appreciated the beauty of the work, and in the end the project was completed. This piece is commemorated by historic markers at Watson School near Bodega, California, and State Route 1 in Valley Ford, California. In December 1976, the country landmarks commission, county of Sonoma designated the Valley Ford site as Historic landmark number twenty-four. Jeanne-Claudes idea to surround eleven islands in Miamis Biscayne Bay was completed on May 4, 1983. It was completed with the aid of four hundred and thirty workers, and was there for two whole weeks. About six hundred thousand m^2 of pink polypropylene floating fabric surrounded the eleven islands was definitely a site to behold. Surrounded Islands covered over 7 miles, and for two weeks, it was seen and enjoyed by the public, from the causeways, the land, water, and air. The bright pink color of the shiny fabric was in tune with the tropical vegetation of the uninhabited verdant island, the light of the Miami sky, and colors of the shallow waters of Biscayne Bay. As with Christo and Jeanne-Claudes previous art projects, Surrounded Islands was entirely financed by the artists through the sale by C.V.J. Corporation of the preparatory pastel and charcoal drawings, collages, lithographs, and early works. On May 4, 1983, out of a total work force of four hundred and thirty people, the u nfurling crew began to blossom the pink fabric. Surrounded Islands was tended to day and night by one hundred and twenty monitors in inflatable boats. Surrounded Islands was a work of art that underlined the various elements and ways in which the people of Miami live between land and water. The project known as Reichstag is easily one of the biggest endeavors Christo and Jeanne-Clade has accomplished, and in my opinion, it is also one of the best. With the support of the President of the Parliament, Rita Sussmuth, Christo and Jeanne-Claude worked to convince the elected Members of Parliament. They went from office to office, writing explanatory letters to each of the six hundred and sixty-two delegates, and innumerable telephone calls and negotiations. On February 25, 1995, after a seventy minute debate at the Parliament, and a Roll Call vote, the Bundestag allowed the project to go ahead. The Bonn government was so enthusiastic about the artwork that Christo and Jeanne-Claude were asked to extend the project. However, since all of their art projects are temporary, this was not possible. The building was unwrapped again on July 7 as planned. Christo explained during a training session for the monitors, Temporary because it challenges our notion of art to challenge the i mmortality of art. We make art not out of gold, silver or marble and think it would stay forever. Non-permanent art will be missedà ¢Ã¢â€š ¬Ã‚ ¦ Also, the artwork cannot stay because it expresses freedom, poetic freedom all projects are about freedom. This project cannot be bought or sold, nobody can charge, can sell tickets. Freedom is the enemy of possession (Hammerstingl). The Wrapper began on June 17, 1995, and it was finished on the 24th. The spectacle was seen by five million visitors before the unveiling began on July 7th. Two times more material was used than was needed, which allowed deep vertical pleats that cascaded down. Because there is always some wind around the Reichstag, the wind was playing with the pleats of the fabric, causing a quiet movement. The color of the fabric and the many deep vertical pleats created a dramatic contrast between light and shadow. This shape transformed the building into a new form. The wrapping of the Reichstag was like building a building, says Christo (Hammerstingl). At a press conference, a reporter from a Jerusalem newspaper asked the artists if they would wrap the Knesset, The Reichstag is the third and last building we wrapped. We have too many other projects to do. We cannot always wrap buildings. Otherwise we would be called the wrappers, Jeanne-Claude answered (Hammerstingl). This project cost $13,000, 000, everything financed by the artists themselves through selling their drawings, collages, and scale models of their projects. All projects are inspired through personal ideas that give the freedom of the work. Freedom, because when it comes down to it, does not have to be justified explains Christo. (Hammerstingl). The last project we will be discussing is The Gates. On January 3, 2005, work began on the installation of The Gates in Central Park in New York City. The official title of the piece is The Gates, Central Park, New York, 1979-2005. The title references the time that passed from their initial proposal until they were able to go ahead with it. Only with the permission of the new mayor of New York, Michael R. Bloomberg, were they able to proceed. It was open to the public only from February 12th until February 27th 2005. Seven thousand five hundred and three gates made of saffron color fabric were placed on paths in Central Park. It was five meters high and had a combined length of 37 km. Bloomberg, a fan of Christo and Jeanne-Claude, presented them with the Doris C. Freedman Award for Public Art for The Gates. They often expressed satisfaction that their concept for their home town of over thirty years was finally realized. An article covering this piece states, The cost of the project was $21 million US dollars which was raised entirely by Christo and Jeanne-Claude selling studies, drawings,  collages, works from the 1950s and 1960s. They do not accept any sponsorship, nor did the city of New York have to provide any money for the project. Christo and Jeanne-Claude donated all the money raised from the sale of souvenirs such as postcards, t-shirts and posters to Nurture New Yorks Nature, Inc. While the engineering, manufacturing and set-up took over a year, about 750 paid employees erected the project in five days and then deployed the fabric of all the gates in half an hour. Around 600 more (Gate-keepers) distributed 1 million free samples of the fabric to visitors. The uniformed Gate-keepers also provided information to visitors about the project, and were responsible for unrolling the gates that had rolled over their crossbars in the high wind.   More workers uninstalled the project in one week, leaving almost no trace and shipping all the materials for r ecycling (Wikipedia). From the pictures with the snow and the vivid color of the gates are a very good contrast of color and the way they seem to jump out against the snow. The pictures arent a great representation of the work, but since their art is temporary, it is the best we can do without being in that certain time and place. This piece is simple in its design, difficult in its realization, and astounding. A little about the artists, Christo and Jeanne-Claude met in October 1958, when he was commissioned to paint a portrait of her mother, Precilda de Guillebon. They had a son together who was born May 11, 1960. Jeanne-Claudes parents were displeased with their relationship, particularly because of Christos refugee status, so they temporarily estranged themselves from their daughter. In 1964, they moved to New York City, poor and lacking fluency in the English language, Christo displayed his work in several galleries, including the well-known Castelli Gallery in New York, and gallery Schmela in Dusseldorf, Germany. Christo Began to create Store Fronts, which he built to scale. The sale of the Store Fronts helped finance larger projects. They have won many, many awards for their art. In 1973, they were nominated for an Academy Award for Best Documentary. In 2004, they won an Achievement in Contemporary Sculpture Award, International Sculpture Center, from Hamilton, New Jersey. In 2005, they were awarded the Doris C. Freedman Award for Public Art by New Yorks mayor. In 2006, they were awarded the Best Project in a Public Space for The Gates, Central Park, New York, 1979-2005. In 2008, they were awarded honorary degrees from Franklin Marshall College. Finally, in 2011, they were awarded more honorary degrees from Occidental College. In closing, Christo and Jeanne-Claude are some of my favorite artists. They have amazing vision for what they want to do in each of their pieces. They dont stop trying for something; for example, The Gates which took 30 years to finally finish. They are, to me, some of the best installation and temporary artists. Their technics may be simple, but it is amazing. They are so popular that in 1978, Charles M. Schulz drew an episode of the show Peanuts where Snoopys doghouse is wrapped in fabric by Christo. In response, Christo constructed a wrapped doghouse and presented it to the Charles M. Schulz Museum in 2003. You cant say enough about what they do, or their drive to do accomplish it. Most people would have given up on their many projects, but they completing them only because of their tenacity and drive to get what they needed done. Theres something to be learned from these two; such as, no matter the odds, or what is put against you, if you never give up, you can and will succeed. Also, staying with the person you love can lead to a tough but fulfilling life. Christo and Jeanne-Claude are one of, maybe even the best, temporary installation types of artists. Work Cited Paul F. Fabozzi. Artists, Critics, Context: Readings in and Around American Art since 1945. Upper Saddle River, N.J. : Prentice Hall, 2002. Werner Hammerstingl. Installation Art. www.Olinda.com. 1998. http://www.olinda.com/ArtAndIdeas/lectures/christo.htm. Wikipedia. Christo and Jeanne-Claude www.wikipedia.com. Dec. 3, 2012. http://en.wikipedia.org/wiki/Christo_and_Jeanne-Claude

The Salton Sea Essay -- Geography

The Salton Sea Introduction The Salton Basin , a below-sea-level depression which extends on the north from Palm Springs , California, to the Gulf of California , in the south. The Salton Sea has undergone historic cycles of filling with water and later drying up. The most recent predecessor to the Sea, that being Lake Cahuilla , last filled this area between 300 to 500 years ago and at one time had a surface elevation above sea level. In 1905 the flooding of the Colorado River was accidentally diverted into the Salton though and thus the Salton Sea was born. When the Colorado River floods retreated in 1907, the surface elevation of the Salton Sea slowly began to drop until the 1930ï ¿ ½s when agricultural drainage from the Imperial and Coachella Valleys sustained its level. Soon after , this Sea was turned into a state recreation area, wildlife refuge and a sport fishery. To this day, agricultural drainage and run-off is the major source of water inflow to the Salton Sea. When it was Healthy When the Sea was healthy it, drew recreationists from all around and was a popular sport fishing site. The marine level of salinity made it a great place to race boats and allowed for the introduction of salt water marine life. With all this attention the north side shore line soon became the Salton Sea State Recreation Area . Not only was this area attractive to people , but it was soon populated by birds and turned into a critical link for flocks of migratory birds along the Pacific Flyway. As a result , the Salton Sea National Wildlife Refuge was established on the south end of the Sea in the 1950ï ¿ ½s.(The Salton Sea Authority and the Bureau of Reclamation , 1997) Current Conditions Today the Salton Sea contains 7.3... ...tm 4. Hunter, Duncan & Lewis, Jerry & Brown, George &Calvert, Ken(1998).Speaker Gingrich, Mary Bono join Salton Sea Task Force in unveiling "Sonny Bono Memorial Salton Sea Reclamation Act". Congressional Salton Sea Task Force. 5. Kellert, S.R. and E.O. Wilson, editors. 1993 The Biophilia Hypothesis. Island Press, Washington, DC 6. NEPA. 1998. The NEPA Fact Sheet. Online. Available http://www.gsa.gov/pbs/pt/call-in/factshet/0397/03_97_9.htm 7. Salton Sea Authority and Bureau of Reclamation .1997. The Salton Sea : Opportunities and Challenges. A brochure. 8. Taylor, Dan. 1998. Audubon Society Inspired to Action by Bird Die -offs . 17 Jan. 1998 . E-mail . Available bkus@sunstroke.sdsu.edu 9. The Salton Sea Authority and the California State Water Commission presentation of : Salton Sea Symposium II - various speakers. The Salton Sea - January 1998

Virtue as Habit Essay -- Aristotle Kant Moral Psychology Papers

Virtue as Habit The aim of this essay is to examine the following question. Does it make a difference in moral psychology whether one adopts Aristotle's ordinary or Immanuel Kant's revisionist definition of virtue as a moral habit? Suppose it is objected, at the outset, that these definitions cannot be critically compared because their moral theories are, respectively, aposteriori and apriori, and so incommensurable. Two points of commensurability and grounds for comparative evaluation are two basic problems that any theory in moral psychology must address. They are moral ignorance (I don't know what I ought to do) and weakness (I don't do what I know I ought to do).(1) In the Nicomachean Ethics (hereafter Ethics), Aristotle maintains that the virtues are formed by repetition as are other habits (see book II, chapters 1-5). "[I]t is by doing just acts that a just man is produced, and by doing temperate acts the temperate man," he explains, and without this kind of habit formation "no one would have even the prospect of being good" (1105b9-12). Further, the "mark" of a good "legislator" and "constitution" is that they: "Make the citizens good by forming habits in them" (1103b4). And in his investigation of the virtue justice, he takes as his "starting point" the ordinary meanings of a "just and an "unjust" man: the latter is "lawless," "grasping," and "unfair"; the former is "law-abiding" and "fair" (V:1129a30-34). In short, Aristotle's intention is to clarify the ordinary meaning of virtue as habit. In the Metaphysical Principles of Virtue (hereafter Virtue), Kant clearly rejects any concept of moral habit-formation by repetition. He writes: Skill (habitus) is a faculty of action and a subjective perfection of ch... ...ichard McKeon. New York: Random House, 1941. —— Poetics. The Basic Works of Aristotle. trans. Ingram Bywater. ed. and introd. Richard McKeon. New York: Random House, 1941. —— Politics. The Basic Works of Aristotle. trans. Benjamin Jowett. ed. and introd. Richard McKeon. New York: Random House, 1941. Kant, Immanuel. The Critique of Practical Reason. trans. Lewis White Beck. Indianapolis: Hackett Publishing Co., 1983 —— Grounding for the Metaphysics of Morals. Ethical Philosophy. trans. James W. Ellington. introd. Warner A. Wick. Indianapolis: Hackett Publishing Co., 1983. —— The Metaphysical Principles of Virtue. Ethical Philosophy. trans. James W. Ellington. introd. Warner A. Wick. Indianapolis: Hackett Publishing Co., 1983. Plato. Republic. The Dialogues of Plato. vol. I. trans Benjamin Jowett. introd. Raphael Demos. New York: Random House, 1937.

Legal History of Bangladesh Short

Legal System has developed gradually in Bangladesh with her growth as a nation over the centuries. Before the advent of British rule this part of the country was under Mughal rule. The Mughals seized power from the Turko-Afghan sultans who ruled the country since the beginning of the 13th century. It was under the Hindu ruler (Aryans) for 1500 years before and after the beginning of Christian era when they conquered the land by vanquishing the indigenous people. During the Turko-Mughal rule the country formed the eastern part of Subah Bangla and, during the British rule, eastern part of the province of Bengal.Historical development of Legal System of Bangladesh: Legal history of Bangladesh can conveniently be studied under five important periods — Hindu Period, Muslim Period, British Period, Pakistan Period and after independence (or Bangladesh period History & Development of Legal System in Bangladesh: Hindu Period to Pakistan Period Md. Ziadul Islam Chowdhury Sadi Department of Law University of Dhaka Legal System has developed gradually in Bangladesh with her growth as a nation over the centuries.Before the advent of British rule this part of the country was under Mughal rule. The Mughals seized power from the Turko-Afghan sultans who ruled the country since the beginning of the 13th century. It was under the Hindu ruler (Aryans) for 1500 years before and after the beginning of Christian era when they conquered the land by vanquishing the indigenous people. During the Turko-Mughal rule the country formed the eastern part of Subah Bangla and, during the British rule, eastern part of the province of Bengal. Historical development of Legal System of Bangladesh:Legal history of Bangladesh can conveniently be studied under five important periods — Hindu Period, Muslim Period, British Period, Pakistan Period and after independence (or Bangladesh period). HINDU PERIOD: Introduction & Sources of Law Legal system in Bangladesh under Hindu period is also known as Aryan legal system because during Hindu period law and legal system were mainly developed by Aryans who migrated from central Asia[1]. After coming to India the Aryans followed certain norms in their conduct with one another. Read also History QuizzesThe rules of conduct (achar) of each class included religious observances which were binding, and violation of the same was expiated by the rituals of penance (prayaschitta). The Brahmins, the priestly class, helped the wrongdoers in performing those rituals. Those rules of conduct were called dharma and included duties and obligations. In course of time it became the dharma of the king to compel the people to observe their rules of conduct and the Brahmins, as the repository of knowledge of those rules, advised the king in administering the same. Legal obligations and their violations were

Short Essay About Sports and Education

The great Duke of Wellington, of Waterloo Victory fame, once saw the boys of Eton public School playing on the field and was moved to say, There our great battles were won† He meant that young lads acquire on the playground not only physical stamina but discipline, the habit of obedience, the will to win, -and these virtues make them good soldiers when their country calls them to the field of battle. It is good to enjoy the delight of running about in the open field and to ‘feel life in every limb’.But that only makes the lesson that we learn, of discipline, obedience and tenacity, all the more pleasing. To develop character not by arid and dry moral lessons, but in the course of our enjoyment of games, is a privilege which we must set store by. The most important lesson that sports of all kinds teach us is a sense of discipline. A good sportsman must always learn to obey the rules of the games and the orders of the captain. He knows the value of the proverb â€⠀œ â€Å"He who knows how to obey will know how to command†.Discipline goes hand in hand with duty. On the playground, each individual has an allotted duty to perform. He has to carry out his share. It is his duty to help in winning games by obeying his captain and maintaining teamwork through concerted movement and display of spirit de crops (team spirit). Another great virtue, which sports help us acquire, is the will to win. Life is a struggle, a constant fight against difficulties. The week-willed man resigns himself to what he calls his fate. Hr belongs to the ranks of the defeated.He is not a sportsman. For a sportsman takes defeats and disappointments as a true part of the game in its stride. Today he is defeated, but he knows that tomorrow he may win. He knows also how to take defeat in a sporting spirit, and to prepare for a greater fight. The true sportsman knows also the value of unity in action. Look at the rowers in a boat from the cockswain to the helmsman, how harmonious and concerted are their strokes. If one of them misses his rhythm, the harmony is destroyed.How often have we not seen on the football ground, a splendid opportunity lost by the selfish desire or individualistic effort of one man to score! It is the same in the cricket field; the same everywhere, not individualistic display for record but to play for the team. Sports should teach us another lesson, which is often ignored, to obey the umpire or the referee whether he is right or wrong. In the hard battle of life, we do not always get justice. Often the verdict goes against us through no fault of ours.A true sportsman takes these ‘slings and arrows of outrageous fortune’ as in the course or part of the game. He is not disheartened but prepares for a further effort; for he is not to question why in defiance. So sports of all kinds are not only good for the body, but they are good for the mind and for the moral make-up, i. e. that is, conducive to building the ch aracter. The lessons learnt on the playground will make better soldiers of us in the battlefield of life, in our war with adversity, illness, opposition and destiny itself.